Bae Assignment

BAE Business Case Study Submitted by Susan Pacheco April 17, 2013 circuit card of Contents P subterfuge 1 administrator Summary3 incite 2 of import force4 range 3 Systemic Issues4 Leadership & cipher vigilance issues4 semi semi semipolitical Pressure to Fast-Track Project5 De crisscross Issues5 Communication Breakdowns6 City Involvement (Delays)6 BAE Conditions on prune Signing (April 1992)6 vocalism 4 Environmental & Root spend a penny abbreviation7 qualitative Analysis7 Project focusing7 People (Un certifiable)8 Build-Design8 Economic & policy- do Con lookrations8 Success with United Airlines9 Part 5 options and/or Options9 Alternative A9Alternative B11 Part 6 Recommendations and Implementation11 Recommendation11 Recommendations Implementation Plan12 Part 7 Monitor and Control13 Part 8 Conclusion13 Part 9 References, Exhibits and vermiform processes13 Part 1 Executive Summary In order to breed the immediate issue of the letter received by the City city manager hol ding us answerable for the check off of the unexampled luggage organisation by charging BAE a penalization of $12k/ mean solar daylight digestdated to October 29, 1993 and as well as takeing a charge back for the $50M tug-and-cart baggage attendant organisation, immediate inciteion and previousity trains to be given to cite this accusation.A exhort analysis of our ramble broadcast and missed milestones with reasons and factual entropy is censorious in defending our position. We sine qua non to prove where trustworthy milestones remote our carry were missed and the domino effect it created and where dependencies to our commitments were broken and by whom. there were umpteen points at which we voiced our concerns on the abide delays and access issues that win hinde ablaze(p) our ability to perform but no one took responsibility or acknowledged the delay.In admission, the Build-Design undertake has in itself created many hurdles and conviction delays out- of-door our control as well as created unfavourable operative t in allys that were unsustainable for our police squads. Our menstruum situation is a mere symptom of a lack of a proper(ip) visit counselling mental synthesis and suffice soulfulnessnel at DIA. Also lack of sponsorship by the city Mayor has created silos and a prejudicial effect on the hurtle flow. The build-design approach is one of the biggest issues but with proper trouble it throne be overcome.Based on BAEs experience and in(predicate) past sound intercommunicateions, we can confidently recommend a bracing organize that has worked in past strays. Given that explanation I feeling we need to propose a drastic change to DIAs Project concern group and propose a raw(a) structure which includes a rude(a)-sprung(prenominal) Project passenger vehicle to over cast the entire working class squad, appointment of surplus team components (see Appendix 1) and reinvigorated hires with the right sk ill sets. chitchat Appendix 2 to see RACI intercellular substance purpose.The proposal is to continue with the new airdrome wide baggage formation implementation only under the condition that DIA restructure their send focus team and obtains sponsorship from the City Mayor and line handler. A team approach must be understood by all parties involved as there be too many moving parts and it is impossible to expect BAE to independently manage all moving parts for what is out of our control especially with a Build-Design plan.This new platform bequeath allow BAE and DIAs members to educate, cast off timely lively decisions, find out assays and critical milestones and hold members accountable for their respective roles. Assuming our proposal is accepted, the overall expected timing from sign contact to observeing risks under the new team structure is 9 weeks. With this plan, a backup system would non be compulsory, thereby avoiding this $50M additional cost. The in for ce(p)ness of this accusation would put BAE at unending financial risk if non bankruptcy.Promptness and priority in discussion this situation is critical. Beyond the financial wedge, there is also the constitution BAE has incessantly enjoyed as being a leader in the marketplace worldwide can also beat a negative effect on current and future proposes with opposite institutions. Part 2 Main Issue City of Denver issued a penalty request of $12k/day backdated to maestro start-up completion date of October 29, 1993 including a $50 M charge back for a tug-and-cart baggage backup system. This main issue is a exit of the systemic issues which are listed below. Part 3 Systemic IssuesLeadership & Project Management issues Shared leading amid city of Denver & Consultant team created many inefficiencies, duplicate work and lack of significant(a) ownership. Additionally no organizational structure change at DIA was ever make to reconcile this new baggage system visualise. Furth er complicating the matter was the communication conduct and roles between city, PMT and consultants were non defined or controlled. All were working in silos. Engineers are inefficiently creating piles of change documentation that are non really managed or communicated.Waste of time retributory to cover their tracks. There is NO real qualified Project jitney to oversee the entire project and bridge the gap between DIA and their pass away Carriers United & Continental, City Council and BAE. We earn been expected to manage the project with everyone working in their silos with no real prevail or team goal or management as a whole. In order to fete things moving a large, we need a DIA counterpart to produce engineering alternatives and make quick decisions on cost, alternatives, computer programming etc.Currently there are too many chefs in the kitchen with no real one person in charge. They had to balance project administration political and social responsibilities. The Work ing Area 4 directors that was depute to us realize no experience in airdrome manifestation, baggage system technologies or new technologies, their main experience is in bodily structure project control management. As much(prenominal) they dont know how to properly support our requests and needs to keep the project deprivation forward.In addition to this since there is no project tutor in charge and lack of proper structure we have to liaise with and to obtain feedback from each Concourse Senior motorcoach and Main terminal figureinal manager. It is apparent that they each operate independently making any agreement difficult as we need to transcend the decisions and derive agreement across all four managers. It is apparent that they each are making independant decisions and trying to tie them all together is very difficult. This creates put up forward bottlenecks for us.Lack of a designated project manager to oversee and manage inputs/outputs from the City, DIA and BAE created a detestable process, digest relationships and lack of accountability and control. Head of DIA project resigned and death of drumhead Airport Engineer Walter Slinger (Oct. 1992), a sound proponent of the baggage system and closely involved in negotiations with us had a significant contact on the project. He was a decisive, em formered decision maker who knew how to address problems and get them resolved promptly. His successor Gail Edmond was not successful in carrying ut the same duties as she was much less experienced and lacked the self-direction, experience and backbone to make much needed quick decisions. Her hands were tied with red tape and took much longer to make any decisions. Overall we had a poor relationship with the management team who had no prior baggage discussion competence or experience. The project was mainly treated as a major(ip) in the public eye(predicate) works project resulting in a lack of support when we needed it for any of our complain ts on timing, access etc semipolitical Pressure to Fast-Track ProjectThere were many factors that influenced and forced this project to a fast-track pace which had some resulting serious consequences both in delays and cost. This fomented the project into a Build-Design project which had created some major delays and cost increases. Some of the other influencing factors are as follows * DBO Date of good Occupancy payback date of January 1, 1994 * Project Management Team pressured to push project ahead at all cost due to long periods of assessment, negotiation and final approvals. governmental pressure from Mayor to force project through a fast-track for their own political stature gain and public optics Design Issues The decision to stick in a new large collection plate aerodrome-wide baggage system came after the building design was already find and we were set about with fully defined project specs which underplayed the immensity and implication of some important requir ements of a baggage system (space, electrical billet needs, building structure requirements, ventilation and air conditioning to dissipate) These issues created kick upstairs bottlenecks and delays in our implementation.Further delays and changes resulted from DIAs lack of consulting with and conducting a needs assessment with their two top carriers United & Continental which accounted for much than than 70% of passenger traffic prior to project start. Their needs were never incorporated into the initial design and program, as a result further changes were requested to design and computer software just 6 months prior to the needed opening date. We had to deal with this even though the automatic and software designs were supposed to be frozen. Communication BreakdownsWe communicated to United we would need 1 more year to get system up and streak but no one listened nor was the message passed along to DIA or the City. We also at many points tried to engage DIA about the delays, access issues and saying bottlenecks that was cause direct delays in our work and we were not given occasion or access when needed. Infact the attitude was that these structure workers were not reporting to BAE to have to listen. City Involvement (Delays) Law restrictions forcing 30% of minority-owned firms and 6% women.This law constrained us to forgo our original proposal of using our own qualified employees in lieu of external outside pack togetherors which estimated an increased cost of nigh 60%. Some of our expertise was lost due to this fact in addition to causing further delays to our project. In Sept. 1993 we went into caution negotiations which lead to a 2 day strike of 300 millwrights that was joined by two hundred electricians over a $8/hr delta pay dispute. We lost the maintenance contract as well as a 2 day delay. BAE Conditions on Contract Signing (April 1992)The conditions and milestones we placed upon accepting the stage business was not respected by the c ity or adhered to, nor was there any eatable made to address issues along the way. ( i. e. freeze dates for mechanical design, software design, designer requirements and the like, all around access, timely completion of certain areas, provision of permanent power, computer rooms these were all set as milestones in our project plan. The city had hold to these conditions with unrestricted access with priority for BAE equipment yet we didnt even have reasonable access.For example * Electricians had to leave work where concrete grinders were creating clouds of dust, * Fumes from chemical sealants forced others to flea * Trucks blocking and restricting * Design obturate dates not adhered to Airlines requested changes to system designing even though mechanical/software designs were frozen. (6 months prior to opening airdrome, still moving equipment around, changing controls and software design * Energy issues City unable to supply clean electricity to the baggage system. Motors and circuitry used in system extremely reactive to power surges and fluctuations.Filters were purchased to correct the problem and a City Worker cancelled a contract without realising that the filters were part of it. Filters arrived several months later in March 1994. 1. braid already begun on terminal and concourses with substantial changes needed on construction to accommodate expanded system. We wrote a letter to city (Jan, 29, 1995) to request prompt action advising of inability to complete project under these conditions with no reply or support. Part 4 Environmental & Root cause Analysis Qualitative AnalysisBAE is a highly qualified with a adore reputation, experienced in projects across the US, Europe and Australia in the development, design, manufacture and install and support of every project it undertook from start to finish. We established a strong position in the US accounting for about 90% of U. S. baggage sorting equipment sales. Since 1972 1994 we had successfully d esigned, manufactured and installed nearly 70 automated baggage treatment systems worth almost $50M at major airports in the US, new-fashioned York, Dallas-Fort Worth, Chicago, San Francisco, Miami, Newark and Pittsburgh.We also consulted in the installation of a $550M terminal for the New capital of South Korea Metropolitan Airport in South Korea. Given our successful history and past accomplishments, it is without a doubt that our management capabilities and expertise in handling various types of projects, with various types of people and countries, proves our commitment, capabilities and expertise in handling labyrinthian variables and situations for every project we undertake. Knowing the strategical importance and complexity of this particular(prenominal) project, we had agreed to take on the project only upon acceptance of certain conditions which was accepted by the City.Many of these conditions were not honored throughout the process causing unnecessary delays, additiona l costs, strained relationships both with the City and DIA management and hurt our reputation Project Management Lack of communication, ownership and project management both at DIA & the City of Denver was the source of this pivotal problem. Since the contract was awarded by the City, they were responsible to give the compliance of the agreed upon conditions and communicate and enforce these conditions to DIA and their employees.In turn DIA did not have a specific Project manager to oversee the entire project as a whole and to act as a liaison between us, the City and their Carriers. Instead we were forced to deal with their respective Area managers one on one which was counterproductive, time consuming and ineffective. We also had to deal with direct changes from the Carriers themselves which further haulted our project. We were setup for harm given the lack of direction and control at DIAs side and the Citys dogmatic approach to making decisions.For a project of this magnitude, there was no consideration made to employ either underlying Managers or Project Manager to oversee, manage and liaise between the terzetto concourse areas. This created some major gaps and no one was there to keep the pulse on the project itself. This was not implemented thus creating a gap in communication, a silo-type attitude amongst decision makers creating no support-system for the major role we played in this implementation. It was apparent that roles between the City, PMT at DIA and Consultants were not defined or controlled.Everyone was working in silos. People (Unqualified) In addition to the management issues, our Assigned Area 4 Managers, lacked the experience in airport construction and baggage system technologies, therefore could not understand the importance and properly support our needs nonetheless handle our requests in a prompt manor. In order to keep things moving along, we needed a DIA counterpart who would be able to produce engineering alternatives and have t he autonomy to make decisions. The death of DIAs headsman Airport Engineer, Walter Slinger created significant impact to our operations as he was decisive and addressed problems promptly. This was an important critical role required for the success of this project. His successor, Gail Edmond lacked the experience, know-how, decision making capabilities and autonomy that further haulted the process. Build-Design The Political pressure to fast-track this project lead to a Build-Design approach to this airport construction which caused many unknown risks and design issues that we had to deal with upon commencement.We were unaware of the construction mountain chain and details to be able to fully understand the scope of the project before undertaking. This also lead to a reactive vs. proactive planning. This posed many unknown risks, changes and modifications to our plans along the way. The instability of this process created many points of change, delays and cost additions and we did our best to manage what was in our control. The point is that many of these delays were not within our control, nor did we have any support from the city to enforce DIAs construction project to meet our agreed upon milestones to meet our own obligations.Economic & Political Considerations The economy in mid 1980s was plummeting with a 37% job loss average across Stapeltons Employment Industries. The Pena administration aggressively promoted the airport relocation, marketing the new airport as a scientificly advanced, state-of-the art structure to draw businesses, import federal capital and fund the innovation of new jobs with bonded debts to overcome the short-term decline in the economy. It was to become a grand project that would be the main showcase for the Public plant life Department.The relationship between BAE and the City was strained primarily because their focus was on airport project speed and bond re-payment and not on the project itself. They were motivated by thei r own public perception in the political realm. Their hands-off approach was detrimental in the success of this project and served more as a crutch and hinderance. When it came to asking for support it felt like they were working against us and not with us. Their strength was not in project management but they had the power to make detect decisions which influenced and affected our overall success.The added pressure of paying the DBO by Jan 1, 1994 forced quick management decisions, early construction without a full scope analysis and risk mitigation not just with BAE but also with DIA. Forced the Build-Design approach which inherently greatly affected our ability to succeed given the lack of adherence to the agreed conditions. Success with United Airlines Once the contract was signed with United totally things went smoothly. The successful implementation of the baggage system with United highlighted what was lacking in dealing with DIA and City directly.The success highlighted an d confirmed our ability to manage the project with a partner who understood the technical and project management needs. Part 5 Alternatives and/or Options Alternative A Continue with the contract for pose the baggage handling system qualified upon the following restructuring & requirements Hiring of new qualified members at DIA. 1. DIA to hire a dedicated qualified Project Manager for the baggage handling system overall project with prior project management experience.One whom understands the key tasks, key players has a strong construction and technological background with project management skills to document, track, address and facilitate the communications between all DIA parties and that of BAE and City Administration. A clear definition of this persons role, decision-making authority and sponsorship by Senior Management is critical. 2. DIA to hire a new Chief Airport Engineer with strong decision making and leadership skills with the autonomy to make decisions and propose Ga il Edmond work under him/her as Chief Associate Engineer. . The new Project Managers goal is to set up all appropriate key stakeholders as proposed in Appendix 1 to conduct 3 main initial sessions with all key stakeholders (*see Appendix 1) to I. Conduct a full risk assessment whereby identifying all risks, prioritise them, have an action plan to mitigate some of them, enounce contingency plans and assign responsible persons to manage the risks. II. Establish a Project Objective Statement, and Create a new project master plan, III.Team member establishment Establish who key players are, their strengths, weaknesses, outlining roles and create a RACI matrix *See Appendix 2 for DIA, BAE, and City for roles and responsibilities for all planning and execution tasks of the project 4. City to hire or appoint a qualified tie with construction, engineering and or technical background experience who is solely assigned to this project with no other conflicting priorities with the autonomy t o make decisions.This persons role is to ensure that legislation doesnt interfere or adversely cause timing risks to the project plan and expedite issues/roadblocks when they swot between DIA, BAE and the city. This proposal is supported by the fact that our design has turn out it pull up stakes work given the proper management setup role model as demonstrated by our successful implemention of the new baggage handling system with United Airlines. The current lack of the right project team members entrust be addressed by this new proposed structure. With the right sponsorship and roject management setup, this willing encourage all to be on the same paginate and working towards the same goal. The added benefit of this is that timelines will be clear and subgross and will hold those truly responsible for delays in their respective areas and table service them and all team members understand the domino affect and impact it can have on the entire project as a whole. This will dis courage the current work silo mentality and will promote an unified meeting of the minds where risks and opportunities for improvement can be quickly identified, communicated and cascaded to the right people.This will also ensure that the right decision makers are present to make judgement calls on plan changes as they come along and not further hold up the process. This should put the plan back on target and give us a working plan going forward where all key players are informed, consulted and responsible for outcomes. The cost of background signal up this new structure is by far a more economical way to get the task done without the added financial bear down of creating a new backup system. Pros * Renewed Focus on project with key roles and responsibilities outlined sets clear goals, accountability and ownership. comprehend risks and enable the team to mitigate them * Clear direction and leadership by all stakeholders and their inputs * Expedite critical milestones and ensure we are on the bridle-path * Maintain reputation * No further $ investment for backup system Cons * New hires required Alternative B Cancel the contract with Denver. founder involvement in any further development unless directly undertake by Carriers. Pros * Focus on core business Cons * Damaged reputation for BAE * Litigation costs * $12k / day penalty Law suit risk Pay back of $50M Baggage system backup plan Part 6 Recommendations and Implementation Recommendation Based on my analysis the strategic impact of cancelling the project at this point would further create a bad reputation for BAE, especially considering the current damage already made to BAE by the unsolicited test plan executed by the mayor and the bad press that has already caused. The decision to continue with the project conditional upon a new team structure is a reasonable request given our past successful history and project management expertise.I feel that we have a strong argument for our position backed up b y facts that are undeniable and can thus prove our honour and lack of responsibility for the delay. This will prove to be a sensitive topic as it appears that it is easier to blame us for the delays. With a mutual understanding about the current situation, I believe it will be easier to urge the Mayor and airmanship director the value the new structure would bring and that a new backup system is not the answer and would cause unnecessary further financial burden, hurt relationships and bad press which no one wants.The success of BAE in installing Uniteds baggage system will be highlighted as an example of the right team structure and how we can achieve the same if we are united in the goal and agree to this plan. Recommendations Implementation Plan Some of the short term elements of the recommendations are already completed or in progress such as building our case / position with regards to reasons for the delays. The following outlines the steps required to make this happen. Tas k Responsible Timing Build case.Engage with Project Manager BAE to identify original plan & milestones and detailed reasons for incomplete tasks. Prepare PPT presentment with key dataWrite back to City Mayor, acknowledging letter and request for a positive meeting to present response with a set date. BAE Project MgrBAE AdminGene DiFonso 3 days2 days1 day Invite to meet with DIA Director of Aviation to present challenges/issues faced throughout the project and the delay outcome. Explain the current position we are in with regards to the citys demands with the objective to gain support for the new proposed structure. Gene DiFonso 1 day fixed Invite DIA Director of Aviation & City Mayor to formal meeting to present project delay reasons/issues & recommendation for continuation of project with recommended structure Gene DiFonso 1 day (fixed) Prepare & Present the proposed structure and Project Team Method Matrix and explain its criticality and past effectiveness in other successful p rojects and why this is necessary even if a backup baggage system is implemented Gene DiFonso 3 days Assume DIAs buy in and that it takes DIA 1 month to hire Project Manager and restructure the Project Management Team Director of Aviation 30 days Work with new Project Management Team to identify construction risks that interfere with our design/implementation plans & come up with put together solutions. Gene DiFonso & PMT 1 week Develop new Strategy with new key Milestones Gene DiFonso, 2 weeks Obtain Buy-In & Committment from key stakeholders City Mayor, Director of Aviation 1 day (fixed Total 9 weeks 1st impact with new Project Team Members Any critical changes to the original plans will be reported promptly to DIA Project Manager and voiced in Team Meetings. Any critical plan changes will equire Sponsor sign offs (acknowledgment and approval of change to plan for reasons outside BAEs control) before BAE continues with implementation. Part 7 Monitor and Control * Week ly internal meetings with BAEs project management team will be conducted to keep pulse on project timelines and areas of risk. * Attend weekly Project Meeting Team meetings to identify risks, action items, schedule changes and react to them. * Submit bi-weekly reports on status to key sponsors & stakeholders. * Hold monthly review meetings with Sponsors Part 8 Conclusion In conclusion, the current difficulties we are experiencing with DIA and City Administration has served as a expensive example of lack of poor management structure for a project of this magnitude.Our past successes can speak for itself in approaching DIA and City Mayor for their support to the new proposal based on our experience. If this new approach is accepted, this will save BAE millions of dollars in lawsuits and cost of new baggage system as charged by the City Mayor. The optics of getting back on track, having a strong management team and continuing with the original plan will serve in favour of all, the May or, our shareholders, as well as redeem our own reputation as leaders in the market. We will then be positioned without a tarnished brand and enjoy further harvest-time opportunities. Part 9 References, Exhibits and Appendixes Appendix 1 New Project Management Team Structure Appendix 2 RACI Matrix example (for initial phase) of new structure